菲迪克(FIDIC)簡(jiǎn)明合同格式-中英對(duì)照版

1、中英文對(duì)照本翻譯校譯審訂菲迪克（FIDIC）文獻(xiàn)譯叢國(guó)際咨詢工程師聯(lián)合會(huì)中國(guó)工程咨詢協(xié)會(huì)編譯1999 年第 1 版Agreement 協(xié)議書General Conditions 通用條件Rules for Adjudication 裁決規(guī)則Notes for Guidance 指南注釋Short Form of Contract簡(jiǎn)明合同格式呂文學(xué) 陳永強(qiáng)唐萍王 川 徐禮章 唐 萍1999年第1 版）（中英文對(duì)照本）（譯者對(duì)譯文的準(zhǔn)確度承擔(dān)全部責(zé)任， 正式使用發(fā)生的爭(zhēng)端，以英文原版為準(zhǔn)）機(jī)械工業(yè)出版社菲迪克（ FIDIC ）授權(quán)書I herewith authorize CNAECto tran

2、slate FIDIC s publications （but not the publications as edited by other organizations） into Chinese and publish them.I agree with your statement, as part of the agreement, that you will:a） Provide FIDIC with 10 copies of the translation per document, andb） Make a statement on the inside cover of the

3、 translationthat the translatortakes fullresponsibility for the accuracy of the translation and that in case of dispute, the original version in English shall prevail.Peter van der TOGTPublications manager 譯文 在此，我授權(quán)中國(guó)工程咨詢協(xié)會(huì)把FIDIC 出版物譯成中文并出版（但是，不包括其他組織編寫的出版物） 。我同意你們的意見，作為協(xié)議的一部分，你們應(yīng)：a） 向 FIDIC 提供每份文件中

4、譯本10 本；b） 在譯文的扉頁(yè)上注明譯者對(duì)譯文的準(zhǔn)確度承擔(dān)全部責(zé)任，如果發(fā)生爭(zhēng)端，以英文原版為準(zhǔn)。出版經(jīng)理： Peter van der TOGTFIDIC is the French acronym for the International Federation of Consulting Engineers.FIDIC （中譯菲迪克）是國(guó)際咨詢工程師聯(lián)合會(huì)的法文縮寫。FIDIC was founded in 1913 by three national associations of consulting engineers within Europe.The objectives o

5、f forming the federation were to promote in common the professional interestsof the member associations and to disseminate information of interest to members of its component national associations.菲迪克（ FIDIC ）是由歐洲三個(gè)國(guó)家的咨詢工程師協(xié)會(huì)于1913 年成立的。組建聯(lián)合會(huì)的上的是共同促進(jìn)成員協(xié)會(huì)的職業(yè)利益，以及向其成員協(xié)會(huì)會(huì)員傳播有益信息。Today FIDIC membership n

6、umbers more than 60 countries from all parts of the globe and the federation represents most of the private practice consulting engineers in the world.今天，菲迪克（ FIDIC ）已有來(lái)自全球各地60 多個(gè)國(guó)家成員協(xié)會(huì)，代表著世界上大多數(shù)私人執(zhí)業(yè)咨詢工程師。FIDIC arranges seminars, conferences and other events in the furtherance of its goals: maintena

7、nce of high ethical and professional standards; exchange of views and information; discussion of problems of mutual concern among member associations and representatives of the international financial institutions; and development of the consulting engineering industry in developing countries.菲迪克（ F

8、IDIC ）舉辦各類研討會(huì)、會(huì)議及其他活動(dòng)，以促進(jìn)其目標(biāo)：維護(hù)高的道德和職業(yè)標(biāo)準(zhǔn)；交流觀點(diǎn)和信息；討論成員協(xié)會(huì)和國(guó)際金融機(jī)構(gòu)代表共同關(guān)心的問(wèn)題，以及發(fā)展中國(guó)家工程咨詢業(yè)的發(fā)展。FIDIC publications include proceedings of various conferences and seminars, information forconsulting engineers, project owners and international development agencies, standard pre-qualification forms, contract d

9、ocuments and client/consultant agreements. They are available from the secretariat in Switzerland.菲迪克（ FIDIC ）的出版物包括：各類會(huì)議和研討會(huì)的文件，為咨詢工程師、項(xiàng)目業(yè)主和國(guó)際開發(fā)機(jī)構(gòu)提供的信息，資格預(yù)審標(biāo)準(zhǔn)格式，合同文件以及客戶與工程咨詢單位協(xié)議書。這些資料可以從設(shè)在瑞士的菲迪克（ FIDIC ）秘書處得到。國(guó)際咨詢工程師聯(lián)合會(huì)INTERNATIONAL FEDERATION OF CONSULTING ENGINEERSFOREWORD 言These Conditions of C

10、ontract have been prepared by the INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS（ FIDIC ） and are recommended for engineering and building work of relatively small capital value. However, depending on the type of work and the circumstances, the Conditions may be suitable for contracts of greater v

11、alue. They are considered most likely to be suitable for fairly simple or repetitive work or work short duration without the need for specialist sub-subtract.國(guó)際咨詢工程師聯(lián)合會(huì)（ FIDIC 菲迪克）已編寫本合同條件，建議用于投資金額相對(duì)較小的工程項(xiàng)目和建筑工程。根據(jù)工程的類型和具體情況，也可以適用于金額較大的合同。本條件可能最適用于不需進(jìn)行專業(yè)分包的相當(dāng)簡(jiǎn)單或重復(fù)性的工程或工期短的工程。The main aim has been to

12、 produce a straightforward flexible document which includes all essential commercial provisions and which may be used for all types of engineering and building work with a variety of administrative arrangements. Under the usual arrangements for this type of contract, the Contractor constructs the Wo

13、rks in accordance with design provided by the Employer or by his representative （if any）. However, this form may also be suitable for contracts which include,or wholly comprise, contractor-designed civil, mechanical and/or electrical works.主要上的是編出一個(gè)簡(jiǎn)明、靈活的文件，包括所有主要的商務(wù)條款，可用于多種管理方式的各類工程項(xiàng)目和建筑工程。這種合同的通常情

14、況是，由承包商按照雇主或其代表（如果有）提供的設(shè)計(jì)實(shí)施工程。這種格式也可用于包括或全部由承包商設(shè)計(jì)的土木、機(jī)械和 / 或電氣工程合同。In addition, the Employer has a choice of valuation methods. Furthermore, although there is no reference to an impartial Engineer, the Employer may appoint an independent Engineer to act impartially, should he wish to do so.另外，雇主可以選擇

15、估價(jià)方法。還有，盡管沒有提到公正的工程師，如果雇主想聘用一個(gè)獨(dú)立的工程師公平行事，他可以這么做。The form is recommendedfor general use, though modificationsmay be required in somejurisdictions.FIDIC considers the official and authentic text to the version in the English language.建議本格式可供通用，便在某些司法管轄區(qū)可能需要一些修改。菲迪克認(rèn)為正式的和權(quán)威性的文本應(yīng)是英文版本。The intention is t

16、hat all necessary information should be provided in the Appendix to the Agreement, the latter incorporating the tenderer s offer and its acceptance in one simple document. TheGeneral Conditions are expected to cover the majority of contracts. Nevertheless, users will be able to introduce Particular

17、Conditions if they wish, to cater for special cases or circumstances. The General Conditions and the Particular Conditions will together comprise the conditions governing the rights and obligations of the parties.編寫意圖是所有必要的信息應(yīng)在協(xié)議書的附錄中給出，協(xié)議書把投標(biāo)人的報(bào)價(jià)和雇主的接受編入一個(gè)簡(jiǎn)單的文件。通用條件應(yīng)能覆蓋多數(shù)合同，如果用戶需要，他們可以加入專用條件以適應(yīng)特定情況

18、或條件的需要。通用條件和專用條件將一起構(gòu)成決定各方權(quán)利和義務(wù)的條件。To assist in the preparation of tender documents using these Conditions, Notes for Guidance are included. These Notes will not become one of the documents forming the Contract. Finally, applicable Rules for Adjudication are also included.為了有助于使用本條件編制招標(biāo)投標(biāo)文件，還包括了指南注釋。

19、這些注釋不是組成合同的一個(gè)文件。最后， 還列入了適用的裁決規(guī)則。The attention of users is drawn to the FIDIC publication “Tendering Procedure ” , whic h presents a systematic approach to the selection oftenderers and the obtaining and evaluation of tenders.用戶請(qǐng)注意菲迪克（ FIDIC ）編寫出版的招標(biāo)程序 ，它提供了選擇投標(biāo)人、招標(biāo)和評(píng)標(biāo)的系統(tǒng)方法。目錄Agreement 協(xié)議書 錯(cuò)誤!未定義書簽。O

20、ffer 報(bào)價(jià) 錯(cuò)誤!未定義書簽。Acceptance 接受 錯(cuò)誤!未定義書簽。Appendix附錄 錯(cuò)誤!未定義書簽。General Conditions 通用條件 錯(cuò)誤!未定義書簽。1 General Provisions 一般規(guī)定 錯(cuò)誤!未定義書簽。Definitions 定義 錯(cuò)誤!未定義書簽。Interpretation 解釋 錯(cuò)誤!未定義書簽。Priority of Documents文件優(yōu)先次序 錯(cuò)誤!未定義書簽。Law 法律 錯(cuò)誤!未定義書簽。Communications 通信交流 錯(cuò)誤!未定義書簽。Statutory Obligations法定義務(wù) 錯(cuò)誤!未定義書簽。2 Th

21、e Employer 雇主 錯(cuò)誤!未定義書簽。Provision of Site 現(xiàn)場(chǎng)的提供 錯(cuò)誤!未定義書簽。Permits and Licences 許可和執(zhí)照 錯(cuò)誤!未定義書簽。Employer s Instructions 雇主的指示 錯(cuò)誤 !未定義書簽。Approvals 批準(zhǔn) 錯(cuò)誤!未定義書簽。3 Employer s Representatives 雇主代表 錯(cuò)誤!未定義書簽。Authorized Person 受權(quán)人 錯(cuò)誤!未定義書簽。Employer s Representative 雇主代表 錯(cuò)誤!未定義書簽。4 The Contractor 承包商 錯(cuò)誤!未定義書簽。Ge

22、neral Obligations 一般義務(wù) 錯(cuò)誤!未定義書簽。Contractor s Representative 承包商代表 錯(cuò)誤 !未定義書簽。Subcontracting 分包 錯(cuò)誤!未定義書簽。Payment of Second Half of Retention后一半保留金的支付錯(cuò)誤 ! 未定義書簽。Performance Security履約擔(dān)保 錯(cuò)誤!未定義書簽。5 Design by Contractor由承包商設(shè)計(jì) 錯(cuò)誤!未定義書簽。Contractor s Design 承包商的設(shè)計(jì) 錯(cuò)誤!未定義書簽。Responsibility for Design 錯(cuò)誤!未定義書簽

23、。6 Employer s Liabilities雇主的責(zé)任 錯(cuò)誤!未定義書簽。Employer s Liabilities雇主的責(zé)任 錯(cuò)誤!未定義書簽。7 Time for Completion 竣工時(shí)間 錯(cuò)誤 !未定義書簽。Execution of the Works 工程的實(shí)施 錯(cuò)誤 !未定義書簽。Programme進(jìn)度計(jì)劃 錯(cuò)誤!未定義書簽。Extension of Time延長(zhǎng)期 錯(cuò)誤!未定義書簽。Late Completion延遲竣工 錯(cuò)誤!未定義書簽。8 Taking-Over 接收 錯(cuò)誤!未定義書簽。Completion 竣工 錯(cuò)誤!未定義書簽。Taking-Over Noti

24、ce 接收通知 錯(cuò)誤 !未定義書簽。9 Remedying Defects修補(bǔ)缺陷 錯(cuò)誤!未定義書簽。Remedying Defects 修補(bǔ)缺陷 錯(cuò)誤!未定義書簽。Uncovering and Testing除去覆蓋和試驗(yàn) 錯(cuò)誤! 未定義書簽。10 Variations and Claims變更和索賠 錯(cuò)誤!未定義書簽。Right to Vary變更權(quán) 錯(cuò)誤!未定義書簽。Valuation of Variations 變更的估價(jià) 錯(cuò)誤 !未定義書簽。Early Warning提早通知 錯(cuò)誤!未定義書簽。Right to Claim 索賠權(quán) 錯(cuò)誤 !未定義書簽。Variation and Cl

25、aim Procedure 變更和索賠程序 錯(cuò)誤 !未定義書簽。11 Contract Price and Payment 合同價(jià)格和付款 錯(cuò)誤 !未定義書簽。Valuation of the Works 工程的估價(jià) 錯(cuò)誤 !未定義書簽。Monthly Statements月報(bào)表 錯(cuò)誤! 未定義書簽。Interim Payment 期中付款 錯(cuò)誤!未定義書簽。Final Payment 最終付款 錯(cuò)誤!未定義書簽。Currency 貨幣 錯(cuò)誤!未定義書簽。Delayed Payment 延誤的付款 錯(cuò)誤!未定義書簽。12 Default 違約 錯(cuò)誤!未定義書簽。Default by Contr

26、actor 錯(cuò)誤!未定義書簽。Default by Employer 雇主違約 錯(cuò)誤!未定義書簽。Insolvency 無(wú)力償債 錯(cuò)誤!未定義書簽。Payment upon Termination 終止的付款 錯(cuò)誤!未定義書簽。13 Risk and Responsibility 風(fēng)險(xiǎn)和職責(zé) 錯(cuò)誤 !未定義書簽。Contractor s Care of the Works 承包商的工程照管 錯(cuò)誤 !未定義書簽。Force Majeure不可抗力 錯(cuò)誤!未定義書簽。14 Insurance 保險(xiǎn) 錯(cuò)誤!未定義書簽。Extent Cover保險(xiǎn)范圍 錯(cuò)誤!未定義書簽。Arrangements約定

27、錯(cuò)誤!未定義書簽。Failure to Insure 未能辦理保險(xiǎn) 錯(cuò)誤 !未定義書簽。15 Resolution of Disputes 爭(zhēng)端的解決 錯(cuò)誤 !未定義書簽。Adjudication 裁決 錯(cuò)誤!未定義書簽。Notice of Dissatisfaction 表示不滿的通知 錯(cuò)誤!未定義書簽。Arbitration 仲裁 錯(cuò)誤!未定義書簽。Particular Conditions 專用條件 錯(cuò)誤!未定義書簽。Agreement協(xié)議書The Employer is of The Contractor is of The Employer desires the execution

28、 of certain Works known as 雇主是：的承包商是：的雇主要實(shí)施的工程名稱為 Offer報(bào)價(jià)The Contractor has examined the documents listed in the Appendix which forms part of this Agreement and offers to execute the Works in conformity with the Contract for the sum of (in words) (in figures) () or such other sum as may be ascertain

29、ed under theContract.This offer, of which the Contractor has submitted two signed originals, may be accepted by theEmployer by signing and returning one original of this document to the Contractor before (date)The Contractor understands that the Employer is not bound to accept the lowest or any offe

30、r received for the Works.Signature: Date: Name: Authorized to sign on behalf of (organization name): Capacity: 承包商已研究了構(gòu)成本協(xié)議書一部分的列于附錄中的文件，按照合同實(shí)施該工程所報(bào)價(jià)格為( 大寫)( 小寫)()或根據(jù)合同可能確定的此類其他總額。承包商已提交兩份本報(bào)價(jià)的簽字原件，雇主可通過(guò)簽字和將本文件一份原件于(日期)前返還給承包商予以接受。承包商理解雇主不一定必須接受收到的對(duì)該工程的最低的或任何報(bào)價(jià)。簽字： 日 期：姓名： 受權(quán)代表：（組織名稱）簽字職務(wù)： Acceptance

31、 接受The Employer has by signing below, accepted the Contractor s offer and agrees that in consideration for the execution of the Works by the Contractor, the Employer shall pay the contractor in accordance with the Contractor. This Agreement comes into effect on the date when the contractor receives

32、one original of this document signed by the Employer.Signature: Date: Name: Authorized to sign on behalf of （organization name）: Capacity: 雇主通過(guò)以下簽字接受承包商的報(bào)價(jià)，并鑒于承包商對(duì)工程的實(shí)施同意按照合同向承包商付款。本協(xié)議書從承包商收到雇主簽字的本文件一份原件的日期開始生效。簽字： 日 期：姓名：受權(quán)代表：（組織名稱）簽字職務(wù)： Appendix 附錄This Appendix forms part of the Agreement本附錄構(gòu)成協(xié)議書的

33、一部分。Note: with the exception of the items for which the Employer s requirements have been inserted, the Contractor shall complete the following information before submitting his offer.（注：除已填入雇主要求的項(xiàng)目外，承包商應(yīng)在提交其報(bào)價(jià)前填寫下列內(nèi)容）Item 項(xiàng)目Sub-Clause Data 內(nèi)容條款號(hào)Document Identification 文件標(biāo)題days 天Law of the country*

34、項(xiàng)目所在國(guó)法律Documents forming the Contract listed in the orderof priority按優(yōu)先次序列出構(gòu)成合同的文件：(delete if not applicable) 文件(如不適用可刪除)(a)TheAgreement協(xié)議書 (b)ParticularConditions 專 用 條件 (c)GeneralConditions通 用 條件 (d)The specification規(guī) 范 要求 (e)Thedrawings圖紙 The Contractor s tendered design承包商的投標(biāo)設(shè)計(jì)(g)The bill of qua

35、ntities 工 程 量表 (h) (i) Time for Completion 竣工時(shí)間 Law of the Contract 合同適用法律Language 語(yǔ)言Provision of Site 現(xiàn)場(chǎng)的提供On the CommencemenDate* 在開工日期Authorized person受權(quán)人員Nameand address of Employer s representative known)雇主代表的姓名和地址(如知道) Performance security (if any)履約擔(dān)保 (如果有)Amount 金額 Form格式Requirements for Con

36、tractor s design (if any) 對(duì)承包商設(shè)計(jì)的要求(如果有)Programme進(jìn)度計(jì)戈U :Time for submission提交時(shí)間Form of programme 進(jìn)度計(jì)戈U的格式Amount payable due to failure to complete由于未能完成工程應(yīng)償付金額(ifPeriod for notifying defects缺陷通知期限&Variation procedure變更程序Daywork rates計(jì)日工作費(fèi)率(details)(細(xì)節(jié))Specification Clause No s 規(guī)范要求條款號(hào)Within 14 days*

37、 of theCommencement Date 開工日期后14*天內(nèi)per day up to a maximum of 10%* of sum stated in the Agreement 每 天 ，超過(guò)協(xié)議書注明總 額的10%*365 days* calculated from the date stated in the notice under Sub-Clause從根據(jù)第款發(fā)出的通知書中注明的日期開始 計(jì)算365*天內(nèi)(details)(細(xì)Valuation of the Works*工程的估價(jià)*Lump sum Price總額價(jià)格Lump sum price with sche

38、dules of rates 總額價(jià)格付費(fèi)率表Lump sum price with bill of quantities總、額價(jià)格附工程量表Remeasurement with tender bill of quantities用投標(biāo)工程量表再測(cè)量Cost reimbursable可補(bǔ)償費(fèi)用Percentage of value of Materials and Plant材料和生產(chǎn)設(shè)備價(jià)值的百分比Percentage of retention保留金百分比Currency of payment支付貨幣Rate of interest 利率Insurances 保險(xiǎn)Materials(deta

39、ils)(details)(details)(details)(details)80%*Plant 90%*5%（細(xì)（細(xì)（細(xì)（細(xì)（細(xì)% per annum 每年Type of cover*保險(xiǎn)類型 Amount of cover* 保險(xiǎn)金額Exclusions* 除外責(zé)任The Works Materials, Plant andThe sum stated in thefees工程、材料、生產(chǎn)設(shè)備和費(fèi)用Agreement plus 15% 協(xié)議書中注明的總額加15%Contractor s Equipment 承包商設(shè)Full replacement cost備全部重置成本Third Par

40、ty injury to persons anddamage to property第三方人身傷害和財(cái)產(chǎn)損壞Workers 工人Other cover* 其他險(xiǎn)Arbitration 仲裁Rules規(guī)貝UAppointing authority 負(fù)責(zé)任命機(jī)構(gòu)Place of Arbitration仲裁地點(diǎn)UNCITRAL Arbitration Rules*(details)聯(lián)合國(guó)國(guó)際貿(mào)易法委員會(huì)仲裁規(guī)則(細(xì)節(jié))President of FIDIC or hisnominee* (details) 菲迪克(FIDIC)的主席或他指定的人*(細(xì)節(jié))The Country*工程所在國(guó)表示適當(dāng)時(shí)由雇

41、主修改。Employer to amend as appropriate *General Conditions通用條件1. General Provisions一般規(guī)定Definitions 定義In the Contract as defined below, the words and expressions defined shall have the following meanings assigned to them, except where the context requires otherwise:在下文定義的合同中，除上下文另有要求外，定義所列的詞語(yǔ)或措辭應(yīng)具有下列給定

42、的含義：The Contract “ Contract means the Agreement and the other documents listed in the Appendix.合同“合同”系指協(xié)議書以及附錄中所列的其他文件。a Specification means the document as listed in the Appendix, includingEmployer s requirements in respect of design to be carried out by the Contractor, if any, and any Variation to

43、 such drawings.“規(guī)范要求”系指附錄中所列的，包括關(guān)于要由承包商進(jìn)行的設(shè)計(jì)的雇主要求的文件（如 果有) ，以及對(duì)此類文件的任何變更?！?Drawings ” means the Employer s drawings of the Works as listed in the Appendix, and any Variation to such drawings.“圖紙”系指附錄中所列雇主的工程圖紙，以及對(duì)此類圖紙的任何變更。Persons“ Employer” means the person named in the Agreement and the legal succ

44、essors inthe title to this person, but not (except with the consent of the Contractor) any assignee.當(dāng)事人 “雇主”系指協(xié)議書中指名的當(dāng)事人和取得此當(dāng)事人資格的合法繼承人，但不指其任何受讓人(除經(jīng)承包商同意外) ?！?Contractor ” means the person named in the Agreement and the legal successors intitle to this person, but no (except with the consent of the

45、Employer) any assignee.“承包商”系指協(xié)議書中指名的當(dāng)事人和取得此當(dāng)事人資格的合法繼承人，但不指其任何受讓人(除經(jīng)雇主同意外) 。“ Party ” means either the Employer or the Contractor. “當(dāng)事方”指雇主或承包商。Dates, Times and Periods 日期、時(shí)間和期限“ CommencementDate ” means the date 14 days after the date the Agreement comes into effect or any other date agreed between

46、 the Parties.“開工日期”系指協(xié)議書生效日期后第 14 天的日期，或雙方同意的其他任何日期。“ Day” means a calendar day. “天”指日歷日?！?Time for Completion ” means the time for completing the Works as stated in theAppendix (or as extended under Sub-Clause , calculated from the CommencementDate.“竣工時(shí)間”系指附錄中注明的、從開工日期算起的完成工程的時(shí)間（或根據(jù)第款的規(guī)定延長(zhǎng)后的時(shí)間）Mone

47、y and Payments 款項(xiàng)和支付“ Cost ” means all expenditure property incurred （or to be incurred） by the Contractor, whether on or off the Site, including overheads and similar charges, but does not include profit.“成本（費(fèi)用） ”指承包商在現(xiàn)場(chǎng)內(nèi)或現(xiàn)場(chǎng)外合理發(fā)生（或?qū)l(fā)生）的全部支出，包括管理費(fèi)用和類似開支，但不包括利潤(rùn)。Other Definitions 其他定義“ Contractor s Eq

48、uipment ” means all apparatus, machinery, vehicles, facilities and other things required for the execution of the Works but does not include Materials or Plant.“承包商設(shè)備”系指為實(shí)施工程需要的全部?jī)x器、機(jī)械、車輛、設(shè)施和其他物品，但不 包括材料或生產(chǎn)設(shè)備?！?Country ” means the country in which the Site is located. “工程所在國(guó)”系指現(xiàn) 場(chǎng)所在的國(guó)家?！?Employer s

49、Liabilities ” means those matters listed in Su-Clause . “雇主的責(zé)任”系指第款中所列的內(nèi)容。“ Force Majeure ” means an exceptional event or circumstance: which is beyond a Party s control; which such Party could not reasonably have provided against before entering into the Contract; which, having arisen, such Party c

50、ould not reasonably have avoided or overcome; and, which is not substantially attributable to the other Party.“不可抗力”系指超出某當(dāng)事方的控制，該方在簽合同前無(wú)法合理預(yù)防；一經(jīng)發(fā)生，該方無(wú)法合理避免或克服，且不能主要?dú)w因于另一方的某種異常事件或情況?！?Material ” means things of all kinds （other than Plant） intended to form or forming part of the permanent work. “材料”系

51、指構(gòu)成或正構(gòu)成永久工程部分的種類物品（生 產(chǎn)設(shè)備除外） ?！?Plant ” means the machinery and apparatus intended to form or forming part of the permanent work.“生產(chǎn)設(shè)備”系指擬構(gòu)成或正構(gòu)成永久工程部分的機(jī)械和儀器。“ Site ” means the places provided by the Employer where the Works are to be executed, and any other places specified in the Contract as forming

52、 part of the Site.“現(xiàn)場(chǎng)”系指由雇主提供的、將要實(shí)施工程的場(chǎng)所，以及合同中指定為現(xiàn)場(chǎng)組成部分的任何其他場(chǎng)所?！?Variation ” means a change to the Specification and / or Drawings （if any） whichis instructed by the Employer under Sub-Clause .“變更”系指雇主根據(jù)第款的規(guī)定做出指示的，對(duì)規(guī)范要求和（或）圖紙（如果有）的改變。“ Works” means all the work and design （if any） to be performed by

53、 the Contractor including temporary work and any Variation.“工程”系指要由承包商實(shí)施的全部工作和設(shè)計(jì)（如果有） ，包括臨時(shí)工程和任何變更。Interpretation 解釋W(xué)orks importing persons or parties shall include firms and organizations. Words importingsingular or one gender shall include plural or the other gender where the context requires.含有當(dāng)事

54、人或當(dāng)事方意思的詞語(yǔ)應(yīng)包括公司或組織。 當(dāng)上下文要求時(shí)， 含有單數(shù)或一種性別意思的詞語(yǔ)應(yīng)包括復(fù)數(shù)或其他性別。Priority of Documents文件優(yōu)先次序The documents forming the Contract are to be taken as mutually explanatory of one another.If an ambiguity or discrepancy is found in the documents, the Employer shall issue any necessary instructions to the contractor,

55、and the priority of the documents shall be in accordance with the order as listed in the Appendix.構(gòu)成合同的各個(gè)文件被認(rèn)為是互作說(shuō)明的， 如果在文件中發(fā)現(xiàn)歧義或矛盾， 雇主應(yīng)向承包商發(fā)出任何必要的批示，文件的優(yōu)先次序應(yīng)按照附錄中列出的順序。Law 法律合同適用的法律在附錄中說(shuō)明。The law of the Contract is stated in the Appendix.Communications 通信交流Wherever provision is made for the giving or issue of any notice, instruction, or other communication by any person, unless otherwise specified such communication shall be wr